Understanding Contractor’s Claims and Time Extensions in FIDIC Contracts

September 6, 2024by Reshma Rose Jacob0

This blog post explores the FIDIC Red Book, widely used in construction contracts for building and engineering works. It specifically examines key sections which deal with Contractor’s Claims and Time Extensions. The article provides a clear overview of the rights and responsibilities of both the Employer and the Contractor. To understand extensions in non-FIDIC contracts, read Navigating Construction Delays: Understanding Extension-of-Time Claims. 

In the world of construction contracts, timing is everything. The FIDIC (International Federation of Consulting Engineers) standard forms of contract provide a structured process for managing claims and extending the completion time for projects. Understanding Clauses 20.1 and 8.4 of the FIDIC Red Book (Conditions of Contract for Construction) is crucial for both Contractors and Employers to navigate the complexities of delays and claims effectively. The article refers to the FIDIC Red Book, specifically the 1999 edition, which is widely used in the construction industry for contracts involving building and engineering works designed by the Employer. This edition outlines the obligations, rights, and procedures for both the Employer and the Contractor, including key clauses such as Clause 20.1 for Contractor’s Claims and Clause 8.4 for Entitlement to Extension of Time. This article provides an in-depth look at these clauses and offers a clear understanding of contractor claims and time extensions, building on the discussion from a previous blog post. 

This blog is a part of our Construction Disputes in the UAE: An Overview pillar blogpost

Contractor’s Claims and Notification Requirements 

Clause 20.1 outlines the strict procedures Contractors must follow when making a claim for additional time or money. The clause mandates that the Contractor must notify the Engineer of any claim within 28 days of becoming aware, or when they should have reasonably become aware, of the circumstances leading to the claim. This 28-day period is critical—failure to meet this deadline results in the Contractor forfeiting their right to an extension of time, additional payment, and releases the Employer from any related liability. 

However, notifying the claim is just the first step. The Contractor is also required to submit a fully detailed claim, complete with all supporting documentation, within 42 days of the event that caused the claim. This timeline begins from the event itself, not from the date of the initial notice. 

Entitlement to Extension of Time 

Clause 8.4 addresses the Contractor’s entitlement to an extension of the Time for Completion, which becomes relevant when work is delayed due to specific causes beyond the Contractor’s control. The clause lists several justifiable causes for extension: 

Variations: Any change in the scope or quantity of work that wasn’t accounted for, unless an adjustment to the completion time was previously agreed upon. 

Contractual Delays: Delays explicitly provided for in the contract, granting the Contractor the right to an extension. 

Adverse Conditions: Exceptionally bad weather or climate conditions that impede progress. 

Unforeseeable Shortages: Unexpected shortages in personnel or materials due to epidemics or government actions that could not have been anticipated. 

Employer-Caused Delays: Delays caused directly by the Employer, their personnel, or other contractors working on the same site. 

For the Contractor to claim an extension, they must notify the Engineer in accordance with Sub-Clause 20.1. The Engineer is then responsible for reviewing the claim, considering past determinations, and may grant an extension. However, the Engineer cannot reduce the extension once it has been granted. 

This clause is designed to protect the Contractor from delays that are out of their control, ensuring that the project timeline can be adjusted to reflect the actual conditions on the ground. 

Flexibility in Timing: The Engineer’s Discretion 

The FIDIC framework also acknowledges that strict adherence to deadlines may not always be feasible. The definition of “Time for Completion” allows for extensions under circumstances outlined in Sub-Clause 8.4. An article on the FIDIC website notes that if there are genuine reasons why deadlines cannot be strictly observed, the Engineer should consider the Contractor’s situation. As long as the Employer is not prejudiced, minor delays of a day or two may be permissible. 

This flexibility underscores the importance of communication and reasonableness in managing construction projects. Both Contractors and Employers benefit from understanding these provisions, ensuring that projects can proceed smoothly, even when unexpected delays occur. 

Steps for Calculating Delays 

Identify Delays

Begin by determining the events that have caused delays in the project. Categorize these delays into excusable delays, which entitle the Contractor to an Extension of Time (EOT), and non-excusable delays, which are the Contractor’s responsibility. 

Critical Path Analysis

Evaluate how the identified delays impact the project’s critical path. Generally, only delays that affect the critical path are eligible for an EOT. 

Submit Notice and Claim

The Contractor must promptly submit a notice of delay followed by a detailed claim to the Engineer, in accordance with the procedures outlined in Clause 20.1. 

Engineer’s Determination

The Engineer will assess the submitted claim and determine the appropriate amount of EOT to be granted, as specified under Clause 8.4. 

Adjust Time for Completion

Based on the EOT granted by the Engineer, the project’s Time for Completion should be adjusted accordingly. 

Calculate Delay Damages

If the Contractor is responsible for delays that exceed the adjusted Time for Completion, delay damages will be calculated at the daily rate specified in the Contract Data, as outlined in Clause 8.7. 

These steps ensure that delays are properly identified, assessed, and accounted for, protecting both the Contractor and the Employer under the terms of the FIDIC Red Book. 

Navigating the intricacies of FIDIC contracts requires a thorough understanding of Clauses 20.1 and 8.4. For Contractors, timely notifications and detailed claims are essential to protect their rights to time extensions and additional payments. Employers and Engineers, on the other hand, must be mindful of these requirements and apply them fairly, considering the realities of project execution. By adhering to these guidelines, both parties can work together to manage delays and ensure successful project completion. 

Disclaimer

The opinions expressed in this blog are those of the respective authors. ATB Legal does not endorse these opinions. While we make every effort to ensure the factual accuracy of the information provided in our blogs, inaccuracies may occur due to changes in the legislative landscape or human errors. It is important to note that ATB Legal does not assume any responsibility for actions taken based on the information presented in these blogs. We strongly recommend verifying information from official sources and consulting with professional advisors to ensure its accuracy and relevance to your specific circumstances.

About ATB Legal

ATB Legal is a full-service legal consultancy in the UAE providing services in dispute resolution (DIFC Courts, ADGM Courts, mainland litigation management and Arbitrations), corporate and commercial matters, IP, business set up and UAE taxation. We also have a personal law department providing advice on marriage, divorce and wills & estate planning for expats.

Please feel free to reach out to us at office@atblegal.com for a non-obligatory initial consultation.

by Reshma Rose Jacob

Reshma is a legal consultant at ATB Legal. She is a law graduate from St. Joseph’s College of Law, Bangalore, and is enrolled with the Bar Council of Kerala.

Leave a Reply

Your email address will not be published. Required fields are marked *

11 + 12 =

Copyright, Privacy Policy, Sitemap, Disclaimer